Legal
Terms of Use
About these terms
These terms govern your use of this website. By browsing the site or sending an enquiry you accept them. If you do not accept them, please do not use the site.
Information on this website
The content on this website is provided for general information about our services. Project descriptions, images, timelines and figures are illustrative. They describe work we have carried out or services we offer, and they are not an offer, a quotation, or a guarantee of any particular outcome, cost or completion date for your project.
Estimates and contracts
Nothing on this website forms a contract. Any scope of work, specification, timeline, material category, exclusion or payment schedule becomes binding only when it is set out in a formal written quotation and contract signed by both parties. Where this website mentions milestones or stages, they are examples only.
Approvals and third parties
We assist with documentation and coordinate with the relevant authorities where a project requires it. We do not control those authorities and we do not guarantee that any approval will be granted, or granted within a particular period. Timelines that depend on third parties — authorities, utility providers or suppliers — are outside our control.
Intellectual property
The logo, brand name, text, images and layout of this website belong to Zainab Builders & Contractors or are used with permission. You may not reproduce or republish them without our written consent.
Links and embedded content
This website links to WhatsApp and embeds a Google Maps panel. We are not responsible for the content, availability or privacy practices of those third-party services.
Limitation of liability
We take reasonable care to keep the information on this website accurate and up to date, but we do not warrant that it is complete or error-free. To the extent permitted by law, we are not liable for any loss arising from reliance on the content of this website. This does not affect our obligations under any contract we enter into with you.
Governing law
These terms are governed by the laws of Pakistan, and the courts of Karachi have jurisdiction over any dispute arising from them.
Contact
Questions about these terms may be sent to info@zainab.clientdemo.site.